Before the organizer and the decoration company negotiated before the decoration of the exhibition hall, in accordance with the relevant laws and regulations, the two parties signed this contract on the basis of equality, voluntariness and consensus on the relevant matters concerning the renovation of the exhibition hall. So how do you write a showroom renovation contract ? The following decoration home decoration network Xiaobian will share the 2018 exhibition hall decoration contract model for everyone, I hope to be helpful to everyone. Exhibition hall decoration contract template The contractor (hereinafter referred to as Party A): Contractor (hereinafter referred to as Party B): In accordance with the "Contract Law of the People's Republic of China" and other relevant laws and regulations, combined with the characteristics of this project, Party A and Party B shall, on the basis of equality, voluntariness and consensus, appoint Party A's decoration and decoration project (hereinafter referred to as the project) Related matters, reached the following agreement: I. Project Overview 1. construction place__________________________________________________________ 2. Construction content (see attached table: project budget table) 3. In the project contracting mode, the two parties agreed to adopt the contracting method of all materials in the construction project of Party B's contract work and package budget. 4. Project duration is ___day, start date ___year ___month ___ day, completion date ___ year ___ month ___ day. Second, the contract price The construction cost of this contract is (RMB) ____________ yuan amount is capitalized as _______________. The above funds do not include purchasing and uncertain items. The final settlement of purchasing and uncertain items is based on the prescribed standards and is settled by actual amount. The above amounts are all pre-tax quotes. (See attached table: Engineering Budget Table.) Third, the construction drawings The construction drawings shall be designed and constructed by Party A and the renderings. Fourth, Party A's work 1. Two days before the start of construction, the conditions for the construction of Party B's admission will be created, including: moving out the interior furnishings or stacking and covering the furniture and furnishings that are difficult to move indoors, so as not to affect the construction principle; 2. Provide and guarantee water and electricity during construction; 3. Responsible for coordinating the relationship between the construction project and the urban management, fire protection and the property where the project is located and the corresponding procedures are completed; 4. If it is necessary to dismantle the structure or equipment pipeline of the original building, it is responsible for going through the relevant approval procedures to the relevant departments; 5. During the construction period, Party A still needs to use part of the area in part, and is responsible for the on-site security and fire protection work. 6. Participate in the supervision of project quality and construction progress, and be responsible for material acceptance, engineering phase acceptance, and project completion acceptance. V. Party B's work 1. Strict implementation of safety construction operation specifications, fire protection regulations, construction specifications and quality standards during construction, and completion of the project on time; 2. Strictly implement the regulations on construction site management in this Municipality, and shall not disturb the people and pollute the environment; 3. Ensure the cleanliness of the construction site, and clean the construction site before the project acceptance; 4. Strictly guarantee the quality of construction, the materials used are of high quality and quantity. Sixth, engineering changes If the project or construction method needs to be changed, both parties shall agree to sign a written change agreement and adjust the relevant project costs and construction period. Seven, material supply Party B shall notify Party A of the materials and equipment provided by Party B according to the contract, and both parties shall jointly accept the materials. Eight construction delays 1. Delays in completion date for the following reasons, confirmed by Party A, the construction period shall be postponed; (1) changes in engineering volume or design changes; (2) force majeure; (3) Party A agrees to other circumstances in which the construction period is postponed. 2. If Party A fails to complete the work in accordance with the contract and affects the construction period, the construction period will be postponed. 3. Party A did not pay the construction cost on time, and the contract period was postponed accordingly. 4. If the responsibility of Party B cannot be completed on time, the construction period will not be postponed; if there is a problem with the quality of the project due to Party B's reasons, Party B shall bear the cost of rework. Nine, quality standards The two parties agreed that the construction quality of the project shall be implemented in accordance with the "Code for Quality of Decorative Engineering" (QBP6016-97). Party B shall not be responsible for the quality of the works caused by the unqualified materials and equipment provided by Party A. Ten, project acceptance and warranty 1. The two parties agreed to conduct the inspection of the materials used in the construction during the construction process, and complete the individual inspections in the completion of the individual projects. 2. After the completion of the project, Party B shall notify Party A of the acceptance, and Party A shall provide a written engineering acceptance form within two days after receiving the acceptance notice. After the project acceptance form is issued, the final payment of the project will be settled within three days. After the settlement of the project payment, handle the handover procedure (see attached table: project settlement statement); 3. The warranty period for this project is one year from the date of signing by both parties. If Party A fails to settle the final payment as required, it shall be deemed to have waived the warranty automatically. XI. Project payment method 1. After the parties agree that the contract will take effect, Party A shall directly pay Party B the construction cost according to the agreement in the following table: 30% three days before the first start; 40% for the second project; and the third pass for the third party. 2. More than half of the project means that the framework project is completed, except for the custom project. XII. Liability for breach of contract 1. If either party to the contract fails to perform the contract or violates the national laws, regulations and relevant policies and regulations, the responsible party shall be liable for the economic loss caused by the fine and compensate the other party for economic losses; 2. If Party A fails to accept the acceptance procedures and Party A uses the finished product in advance or automatically uses the finished product to cause losses, Party A shall be responsible; 3. If, for one reason, the contract cannot continue to be performed, the party shall promptly notify the other party to terminate the contract, and the responsible party shall compensate the other party for the corresponding economic loss; 4. If Party A fails to pay the second (three) project payment on time, each party shall pay the liquidated damages of _________ yuan to each other for one day delay. Party A shall delay the transfer for more than 5 days, and Party B has the right to withdraw from the construction site, thereby causing the project to be postponed. Party A is responsible. 5. Due to the reasons of Party B, the project was delayed, and one-thousandth of the total amount of the project was paid to the other party for each day of delay as a penalty. XIII. The solution to the contract dispute If the dispute between the two parties is not resolved, the following method shall be adopted; 1. Apply to the Contract Arbitration Commission of Baoding City Administration for Industry and Commerce for arbitration; 2. Sue in Baoding City People's Court. Fourteen, matters needing attention During the construction period, Party A shall hand over the keys to the construction team of Party B _________ for custody. 15. Supplementary Provisions 1. This contract shall become effective after being signed by both parties. 2. This contract is made in two copies, one for each party. 3. The contract is automatically terminated after it has been fulfilled. 4. The agreement for engineering change is as valid as this contract. 5. The funds generated in this project shall be subject to the attached “Project Budget Tableâ€, and the final settlement shall be settled by the actual amount of work incurred. Remarks: _________________________________________________________________________ _______________________________________________________________________________ Party A (Signature) _____________ Party B Representative (Signature) _____________ ____________________________________________ The above is how Xiaobian brought you the exhibition hall decoration contract? For the entire contents of the 2018 exhibition decoration contract model, I believe that everyone has a basic understanding of the exhibition decoration contract after reading this article. If you want to know more about decoration consultation, please click to enter the decoration knowledge channel. More related wonderful reading: What materials are needed for the decoration of the exhibition hall? Exhibition hall decoration materials How to do the decoration of the exhibition hall? Detailed explanation of the decoration process of the exhibition hall How to design the exhibition hall decoration? Exhibition decoration design How is the exhibition decoration budget allocated? How to see the exhibition hall decoration offer? How is the layout of the exhibition hall good? Exhibition feng shui layout knowledge
Window Screen is usually made of Galvanized Iron Wire, stainless steel wire and aluminum wire. It is widely used as mosquito screen, window screen, door screen and filter screen. The plain wave one is very common. The plain wire cloth is not crimped before weaving, with the same diameter warp and shute Wires woven in a simple over and under pattern.
Features
Ÿ Mesh:
Number of openings per inch in horizontal and vertical directions.
Ÿ Woven
type: Plain weave.
Ÿ Type
of edge: Rough selvedge, wrapped selvedge.
Window Screen Galvanized Wire Mesh Screen,Aluminum Wire Screen,Stainless Steel Wire Mesh DINGZHOU TIAN YILONG METAL PRODUCTS CO., LTD. , http://www.wiremeshsolution.com
